NOTICE TO CONTRACTORS MASSACHUSETTS EXECUTIVE OFFICE FOR ADMINISTRATION AND FINANCE DIVISION OF CAPITAL ASSET MANAGEMENT AND MAINTENANCE
Electronic Bids submitted in the format furnished by the Division of Capital Asset Management & Maintenance (DCAMM) and clearly identified as a bid will be received through DCAMM’s E-Bid Room at www.bidexpress.com/businesses/10279/home no later than the date and time specified and will forthwith be publicly opened remotely by DCAMM Bid Room personnel and read aloud over a conference call line. Persons interested in accessing the remote bid opening can do so by using the following phone number: Audio Conferencing Dial-In Number (617) 315-0704, Meeting Number 2333 916 4237#. If prompted for attendee ID, please press #.
Mass. State Project No. MMP-39
Mechanical and Plumbing Preventive Maintenance and Control Center Monitoring Contract for Certain Buildings in Boston, MA
General Bids at 2:00 PM: June 10, 2026
This Project bid in accordance with M.G.L. Chapter 30 Section 39M.
E.C.C: $16,591,003
This project is scheduled for 1095 calendar days to substantial completion, with up to three (3) one-year renewals. Scope: Experienced and qualified Mechanical and Plumbing Preventive Maintenance Service contractor sought, either licensed as a Mechanical, Refrigeration and Plumbing Contractor to enter a Mechanical and Plumbing Preventive Maintenance and Control Center Monitoring Contract for the Massachusetts State House, McCormack, Hurley, and Lindemann Buildings in Boston, Massachusetts.
A Pre-Bid/Site Visit will be held on 05/21/26 at 11:30 AM. Meet in the McCormack Building Lobby, past security, outside Room 109. Bring valid ID. Remaining sites to follow. Expected finish at 1:30 PM.
Bid documents for this project may be accessed or downloaded at no cost to potential bidders exclusively through DCAMM’s E-Bid Room https://www.bidexpress.com/businesses/10279/home A hard copy set can be made available for viewing in DCAMM’s Bid Room located at One Ashburton Place, 15th Floor, Boston, MA during normal business hours by appointment only by contacting DCAMM’s Bid Room.
In order to access bid documents and submit bids through DCAMM’s E-Bid Room potential bidders must first be verified by DCAMM’s Bid Room and then register with the E-Bid Room vendor. Instructions on the processes can be found on DCAMM’s website www.mass.gov/dcamm/bids or contact DCAMM’s Bid Room at [email protected] or (617) 727-4003.
NOTICE TO CONTRACTORS MASSACHUSETTS EXECUTIVE OFFICE FOR ADMINISTRATION AND FINANCE DIVISION OF CAPITAL ASSET MANAGEMENT AND MAINTENANCE
Electronic Bids submitted in the format furnished by the Division of Capital Asset Management & Maintenance (DCAMM) and clearly identified as a bid will be received through DCAMM’s E-Bid Room at www.bidexpress.com/businesses/10279/home no later than the date and time specified and will forthwith be publicly opened remotely by DCAMM Bid Room personnel and read aloud over a conference call line. Persons interested in accessing the remote bid opening can do so by using the following phone number: Audio Conferencing Dial-In Number (617) 315-0704, Meeting Number 2333 916 4237#. If prompted for attendee ID, please press #.
Mass. State Project No. MMP-40
Fire Alarm and Fire Protection Maintenance Services for Massachusetts State House in Boston, MA
General Bids at 2:00 PM: June 8, 2026
This Project bid in accordance with M.G.L. Chapter 30 Section 39M.
E.C.C: $247.944
This project is scheduled for 1095 calendar days to substantial completion, with up to three (3) one-year renewals. Scope: DCAMM seeks the services of an experienced and qualified Fire Alarm Systems and Equipment and Fire Protection Systems and Equipment contractor, either licensed as an Electrical Contractor in Massachusetts or employs staff with Technician D Licenses, to enter a Fire Alarm and Protection Systems and Equipment Preventive Maintenance Service Contract to include testing, inspection, preventative maintenance (including all PM required parts and materials.
A Pre-Bid/Site Visit will be held on 05/19/26 at 10:00 AM. Meet at the State House in the loading dock garage, on Derne Street. Bring valid ID.
Bid documents for this project may be accessed or downloaded at no cost to potential bidders exclusively through DCAMM’s E-Bid Room https://www.bidexpress.com/businesses/10279/home A hard copy set can be made available for viewing in DCAMM’s Bid Room located at One Ashburton Place, 15th Floor, Boston, MA during normal business hours by appointment only by contacting DCAMM’s Bid Room.
In order to access bid documents and submit bids through DCAMM’s E-Bid Room potential bidders must first be verified by DCAMM’s Bid Room and then register with the E-Bid Room vendor. Instructions on the processes can be found on DCAMM’s website www.mass.gov/dcamm/bids or contact DCAMM’s Bid Room at [email protected] or (617) 727-4003.
NOTICE TO TRADE CONTRACTORS REQUEST FOR TRADE CONTRACTOR QUALIFICATIONS
The MASSACHUSETTS PORT AUTHORITY is soliciting Statements of Qualifications from TRADE CONTRACTORS interested in performing work for L1918 AIR TRAFFIC CONTROL TOWER PHASE 2A. The Authority is seeking Qualification Statements from Trade Contractors who have a demonstrated experience in the construction and implementation of similar work in terms of scale and complexity as required for the LOGAN INTERNATIONAL AIRPORT. In accordance with Massachusetts construction manager at-risk requirements, MGL Chapter 149A Section 8, Qualification Statements are being requested from trade contractors capable of performing the following classes of work: MASONRY, MISCELLANEOUS METALS, ROOFING, TILE, ACOUSTICAL TILE, RESILIENT FLOORS, PAINTING, FIRE PROTECTION, PLUMBING, HEATING, VENTILATION AND AIR CONDITIONING, AND ELECTRICAL.
The estimated cost of the trade contractors’ portion of this phase of the Project is approximately $5,903,669.00 and the construction duration for this phase is approximately 14 months. The estimated value of work to be performed by trade contractors is as follows:
Masonry .................................................................. $25,000.00 Miscellaneous Metals .............................................. $25,000.00 Roofing ................................................................... $25,000.00 Tile ....................................................................... $145,240.00 Acoustical Tile ......................................................... $25,000.00 Resilient Floors ....................................................... $25,000.00 Painting .................................................................. $72,008.00 Fire Protection ...................................................... $791,200.00 Plumbing ........................................................... $1,169,000.00 Heating, Ventilation and Air Conditioning ............. $1,556,449.00 Electrical ........................................................... $2,044,772.00
The Authority is implementing this project in accordance with MGL Chapter 149A, Sections 1 thru 13. This selection of trade contractors conforms to MGL Chapter 149A, Section 8, subsections (b) to (k) inclusive. This Request for Qualifications (RFQ) will be utilized to prequalify trade contractors capable and experienced in the construction of parking garages and terminal buildings. The Authority shall utilize a two-step process including the prequalification of trade contractors based on an evaluation of the Statement of Qualifications received in response to this solicitation, followed by an Invitation to Bidders that will only be issued to the prequalified trade contractors. A Prequalification Committee consisting of four representatives, one each from the Designer and the CM at Risk and two Massport staff. This Prequalification Committee will be conducting a qualifications-based evaluation of submittals received from interested trade contractors in order to identify prequalified trade contractors who will be invited to respond to a written Invitation to Bidders. Please note that the Authority is not utilizing this process to prequalify subcontractors who are not trade contractors which shall be done separately in accordance with MGL C149A, Section 8, subsection (j).
Qualification Statements shall be evaluated in accordance with the following criteria; (1) Management Experience; (2) Project References including a Public Project Record and (3) Capacity to Complete including a demonstration that the contractor has the financial stability and long-term viability to successfully implement the Project.
A Supplemental Information Package which will provide more details on the scope of the Project as well as the selection process and evaluation criteria shall be available as of MAY 13, 2026 on Bid Express, the Capital Bid Opportunities webpage of Massport http://www.massport.com/massport/business/bids-opportunities/capital-bids as an attachment to the original Legal Notice, and on COMMBUYS (www.commbuys.com) in the listings for this project.
Responses shall be addressed to Luciana Burdi, Intl. Assoc. AIA, CCM, MCPPO, NAC, Chief Infrastructure Officer, and received no later than 12:00 PM Local Time on JUNE 11, 2026, via Bid Express https://www.bidexpress.com/businesses/27137/home
All questions relative to your submission shall be directed to [email protected]. In the subject line of your email, please reference the MPA Project Name and Number. It is strictly prohibited for any proponent to contact anyone else from Massport about this project from the time of this solicitation until award of the project to the successful proponent.
MASSACHUSETTS PORT AUTHORITY Richard A. Davey CEO & Executive Director
MASSACHUSETTS PORT AUTHORITY
NOTICE TO CONTRACTORS
Electronic General Bids for MPA Contract No. H288-C3, INSTALL RUNWAY 5 END EMAS, LAURENCE G. HANSCOM FIELD, BEDFORD, MASSACHUSETTS, will be received through the internet using Bid Express until the date and time stated below, and will be posted on www.bidexpress.com immediately after the bid submission deadline.
Electronic bids will be received by the Massachusetts Port Authority until 11:00 A.M. local time on WEDNESDAY, JUNE 3, 2026, immediately after which the electronic bids will be opened and posted publicly on Bid Express.
No paper copies of bids will be accepted.
NOTE: A PRE-BID CONFERENCE WILL BE HELD IN PERSON AT THE L.G.
HANSCOM FIELD TERMINAL BUILDING, THIRD FLOOR – CONFERENCE ROOM, 200 HANSCOM DR, BEDFORD, MA, AT 9:00 AM (LOCAL TIME) ON WEDNESDAY, MAY 20, 2026.
The work includes PAVEMENT MILLING, ASPHALT PAVING, PAVEMENT MARKINGS, PAVEMENT CRACK REPAIR, INSTALLATION OF ENGINEERED MATERIAL ARRESTING SYSTEM (EMAS).
Bid documents will be made available beginning WEDNESDAY, MAY 13, 2026.
Bid documents for this project may be accessed or downloaded at no cost to potential bidders exclusively through www.bidexpress.com/businesses/27137/home in the listing for this Project.
The estimated contract cost is ONE MILLION FIVE HUNDRED THIRTY-FIVE THOUSAND DOLLARS ($1,535,000).
A proposal guaranty shall be submitted with each General Bid consisting of a bid deposit for five (5) percent of the value of the bid; when sub-bids are required, each must be accompanied by a deposit equal to five (5) percent of the sub-bid amount in the form of a bid bond in the name of which the Contract for the work is to be executed. The bid deposit shall be (a) in a form satisfactory to the Authority, (b) with a surety company qualified to do business in the Commonwealth and satisfactory to the Authority, and (c) conditioned upon the faithful performance by the principal of the agreements contained in the bid.
Bidders must submit a Buy American Certificate with all bids or offers on AIP funded projects. Bids that are not accompanied by a completed Buy American Certificate must be rejected as nonresponsive.
The successful Bidder will be required to furnish a performance bond and a labor and materials payment bond, each in an amount equal to 100% of the Contract price. The surety shall be a surety company or securities satisfactory to the Authority. Attention is called to the minimum rate of wages to be paid on the work as determined under the provisions of Chapter 149, Massachusetts General Laws, Section 26 to 27G, inclusive, as amended. The Contractor will be required to pay minimum wages in accordance with the schedules listed in Division II, Special Provisions of the Specifications, which wage rates have been predetermined by the U. S. Secretary of Labor and / or the Commissioner of Labor and Industries of Massachusetts, whichever is greater.
The successful Bidder will be required to purchase and maintain Bodily Injury Liability Insurance and Property Damage Liability Insurance for a combined single limit of $5,000,000. Said policy shall be on an occurrence basis and the Authority shall be included as an Additional Insured. See the insurance sections of Division I, General Requirements and Division II, Special Provisions for complete details.
The Authority, in accordance with the provisions of Title VI of the Civil Rights Act of 1964 (78 Stat. 252, 42 USC §§ 2000d to 2000d-4) and the Regulations, hereby notifies all bidders or offerors that it will affirmatively ensure that for any contract entered into pursuant to this advertisement, all bidders/proposers will be afforded full and fair opportunity to submit bids in response to this invitation and no businesses will be discriminated against on the grounds of race, color, national origin (including limited English proficiency), creed, sex (including sexual orientation and gender identity), age, or disability in consideration for an award.
The General Contractor is required to submit a Certification of Non-Segregated Facilities prior to award of the Contract, and to notify prospective subcontractors of the requirement for such certification where the subcontract exceeds $10,000.
A Contractor having fifty (50) or more employees and his subcontractors having fifty (50) or more employees who may be awarded a subcontract of $50,000 or more will, within one hundred twenty (120) days from the contract commencement, be required to develop a written affirmative action compliance program for each of its establishments.
Compliance Reports - Within thirty (30) days of the award of this Contract the Contractor shall file a compliance report (Standard Form [SF 100]) if:
(a) The Contractor has not submitted a complete compliance report within twelve (12) months preceding the date of award, and
(b) The Contractor is within the definition of “employer” in Paragraph 2c(3) of the instructions included in SF100.
The contractor shall require the subcontractor on any first tier subcontracts, irrespective of the dollar amount, to file SF 100 within thirty (30) days after the award of the subcontracts, if the above two conditions apply. SF 100 will be furnished upon request. SF 100 is normally furnished Contractors annually, based on a mailing list currently maintained by the Joint Reporting Committee. In the event a contractor has not received the form, he may obtain it by writing to the following address:
Joint Reporting Committee 1800 G Street Washington, DC 20506
Complete information and authorization to view the site may be obtained from the Capital Programs Department Office at the Massachusetts Port Authority. The right is reserved to waive cb any informality in or reject any or all proposals.
MASSACHUSETTS PORT AUTHORITY Richard A. Davey CEO & Executive Director
Commonwealth of Massachusetts The Trial Court Suffolk Probate and Family Court 24 New Chardon Street, Boston, MA 02114 (617) 788-8300
Docket No. SU05W1150PA1
Summons By Publication
James Bowdre, Plaintiff(s) v. Emma Speed, Defendant(s)
To the above-named Defendant(s): Emma Speed
A Complaint has been presented to this Court by the Plaintiff(s), James Bowdre, seeking the Court to make such orders as it deems expedient concerning Judicial Review filed on: 04/22/2025.
You are required to serve upon Katherine Coombs, Esq.— whose address is Veterans Legal Services PO Box 8457 Boston, MA 02114 your answer on or before June 3, 2026. If you fail to do so, the court will proceed to the hearing and adjudication of this action. You are also required to file a copy of your answer in the office of the Register of this Court at 24 New Chardon Street, Boston, MA 02114.
Witness, Hon. Janine Rivers, Esq., First Justice of said Court at Suffolk, this 22nd Day of April 2026.
Stephanie L. Everett, Esq.
Register of Probate
Commonwealth of Massachusetts The Trial Court Suffolk Probate and Family Court 24 New Chardon Street, Boston, MA 02114 (617) 788-8300
Docket No. SU26P0564EA
CITATION ON PETITION FOR FORMAL ADJUDICATION
Estate of: Doris Loretta Ammons Date of Death: 12/10/2025
To all interested persons:
A Petition for Formal Adjudication of Intestacy and Appointment of Personal Representative has been filed by Pauline Adams-Malgas of Roslindale MA and Jimmishea Nichols of Randolph MA requesting that the Court enter a formal Decree and Order and for such other relief as requested in the Petition.
The Petitioner requests that: Pauline Adams-Malgas of Roslindale MA and Jimmishea Nichols of Randolph MA be appointed as Personal Representative(s) of said estate to serve Without Surety on the bond in supervised administration
IMPORTANT NOTICE You have the right to obtain a copy of the Petition from the Petitioner or at the Court. You have a right to object to this proceeding. To do so, you or your attorney must file a written appearance and objection at this Court before: 10:00 a.m. on the return day of 06/09/2026. This is NOT a hearing date, but a deadline by which you must file a written appearance and objection if you object to this proceeding. If you fail to file a timely written appearance and objection followed by an affidavit of objections within thirty (30) days of the return day, action may be taken without further notice to you.
UNSUPERVISED ADMINISTRATION UNDER THE MASSACHUSETTS UNIFORM PROBATE CODE (MUPC) A Personal Representative appointed under the MUPC in an unsupervised administration is not required to file an inventory or annual accounts with the Court. Persons interested in the estate are entitled to notice regarding the administration directly from the Personal Representative and may petition the Court in any matter relating to the estate, including the distribution of assets and expenses of administration.
WITNESS, Hon. Janine D Rivers, First Justice of this Court. Date: May 05, 2026
Stephanie L. Everett, Esq.
Register of Probate
Commonwealth of Massachusetts The Trial Court Suffolk Probate and Family Court 24 New Chardon Street, Boston, MA 02114 (617) 788-8300
Docket No. SU26P0900EA
CITATION ON PETITION FOR FORMAL ADJUDICATION
Estate of: Dennis Alvin Stewart Also known as: Dennis Stewart Date of Death: 09/18/2024
To all interested persons:
A Petition for Formal Probate of Will with Appointment of Personal Representative has been filed by Shawn Noel, Sr. of Brockton, MA requesting that the Court enter a formal Decree and Order and for such other relief as requested in the Petition. The Petitioner requests that Shawn Noel, Sr. of Brockton, MA be appointed as Personal Representative(s) of said estate to serve Without Surety on the bond in unsupervised administration.
IMPORTANT NOTICE You have the right to obtain a copy of the Petition from the Petitioner or at the Court. You have a right to object to this proceeding. To do so, you or your attorney must file a written appearance and objection at this Court before: 10:00 a.m. on the return day of 06/10/2026. This is NOT a hearing date, but a deadline by which you must file a written appearance and objection if you object to this proceeding. If you fail to file a timely written appearance and objection followed by an affidavit of objections within thirty (30) days of the return day, action may be taken without further notice to you.
UNSUPERVISED ADMINISTRATION UNDER THE MASSACHUSETTS UNIFORM PROBATE CODE (MUPC) A Personal Representative appointed under the MUPC in an unsupervised administration is not required to file an inventory or annual accounts with the Court. Persons interested in the estate are entitled to notice regarding the administration directly from the Personal Representative and may petition the Court in any matter relating to the estate, including the distribution of assets and expenses of administration.
WITNESS, Hon. Janine D Rivers, First Justice of this Court. Date: May 06, 2026
Stephanie L. Everett, Esq.
Register of Probate
Commonwealth of Massachusetts The Trial Court Suffolk Probate and Family Court 24 New Chardon Street, Boston, MA 02114 (617) 788-8300
Docket No. SU26D0572DR
Divorce Summons by Publication and Mailing
Clifford E Reed vs. Paula L Reed
To the Defendant:
The Plaintiff has filed a Complaint for Divorce requesting that the Court grant a divorce for Irretrievable Breakdown.
The Complaint is on file at the Court.
An Automatic Restraining Order has been entered in this matter preventing you from taking any action which would negatively impact the current financial status of either party. SEE Supplemental Probate Court Rule 411.
You are hereby summoned and required to serve upon: Clifford E Reed, 1295 Commonwealth Ave Apt 1, Allston, MA 02134 your answer, if any, on or before 06/25/2026. If you fail to do so, the court will proceed to the hearing and adjudication of this action. You are also required to file a copy of your answer, if any, in the office of the Register of this Court.
WITNESS, Hon. Janine D Rivers, First Justice of this Court. Date: April 29, 2026
Stephanie L. Everett, Esq.
Register of Probate
Commonwealth of Massachusetts The Trial Court Suffolk Probate and Family Court 24 New Chardon Street, Boston, MA 02114 (617) 788-8300
Docket No. SU25D2273DR
Divorce Summons by Publication and Mailing
Francheska Yenise Fortuna vs. Feliciano Fortuna Sanchez
To the Defendant:
The Plaintiff has filed a Complaint for Divorce requesting that the Court grant a divorce for irretrievable breakdown.
The Complaint is on file at the Court.
An Automatic Restraining Order has been entered in this matter preventing you from taking any action which would negatively impact the current financial status of either party. SEE Supplemental Probate Court Rule 411.
You are hereby summoned and required to serve upon: Francheska Yenise Fortuna, 72 Weaver Way, Boston, MA 02119 your answer, if any, on or before 06/24/2026. If you fail to do so, the court will proceed to the hearing and adjudication of this action. You are also required to file a copy of your answer, if any, in the office of the Register of this Court.
WITNESS, Hon. Janine D Rivers, First Justice of this Court. Date: April 23, 2026
Stephanie L. Everett, Esq.
Register of Probate
Commonwealth of Massachusetts The Trial Court Suffolk Probate and Family Court 24 New Chardon Street, Boston, MA 02114 (617) 788-8300
Docket No. SU24D2282DR
Divorce Summons by Publication and Mailing
Jahirin A Peguero vs. Raul Emilio Nova
To the Defendant:
The Plaintiff has filed a Complaint for Divorce requesting that the Court grant a divorce for Irretrievable Breakdown.
The Complaint is on file at the Court.
An Automatic Restraining Order has been entered in this matter preventing you from taking any action which would negatively impact the current financial status of either party. SEE Supplemental Probate Court Rule 411.
You are hereby summoned and required to serve upon: Jahirin A Peguero, 26 Wabeno Street, Apt #3, Boston, MA 02121 your answer, if any, on or before 06/03/2026. If you fail to do so, the court will proceed to the hearing and adjudication of this action. You are also required to file a copy of your answer, if any, in the office of the Register of this Court.
WITNESS, Hon. Janine D Rivers, First Justice of this Court. Date: April 21, 2026
Stephanie L. Everett, Esq.
Register of Probate
